Site work, paving and new construction of a mixed-use development in Carrabelle, Florida. Completed plans call for site work for a playground / park / athletic field; for paving for a playground / park / athletic field; for the construction of a 743-square-foot pre-engineered storage facility; pre-engineered storage facility; and water / sewer project.

The Franklin County Board of County Commissioners Will Receive Sealed Bids From Any Qualified Person, Company or Corporation Interested in Constructing: Franklin County Island View Park Frdap Improvements Projects Description: Additions to Island View Park Which Consist of Approximately 743 Sq Ft of Concrete Pad for Modular Restroom and Covered Pavilion, a 16x30 Pre-engineered Pole Barn for the Pavilion Cover, a Modular Restroom Facility and Utility Connections, Etc. Island View Park is Located Approximately 1.8 Miles East of Carrabelle, Florida. All Bidders Shall Comply With All Applicable State and Local Laws Concerning Licensing Registration and Regulation of Contractors Doing Business to the State of Florida. Franklin County Encourages Minority Business Enterprises to Respond to This Bid Invitation. The Board of County Commissioners Reserves the Right to Waive Informalities in Any Bid, to Accept and/or Reject Any or All Bids, and to Accept the Bid That in Their Judgment Will Be in the Best Interest of Franklin County. All Bids Shall Remain Firm for a Period of Sixty Days After the Opening. Completion Date for This Project Will Be 90 Days From the Date of the Notice to Proceed Presented to the Successful Bidder. Liquidated Damages for Failure to Complete the Project on the Specified Date Will Be Set at $250.00 Per Day. Question Deadline 05/18/2026 If You Have Any Questions, Please Call Erin Griffith at (850) 653-5143. All Technical Questions Must Be Addressed in Writing and Emailed to Erin Griffith at Erin@franklincountyflorida.com