Site work and paving for a sidewalk / parking lot in Bristol, Connecticut. Completed plans call for site work for a sidewalk / parking lot; and for paving for a sidewalk / parking lot.

The awarded contractor will be required to secure a Performance Bond and a Labor and Materials Bond, each in the amount of 100% of the contract award, provided by a surety licensed to do business in the State of Connecticut Bid Bond issued by a surety licensed to do business in the State of Connecticut, in the amount of 10% of the bidders base bid amount. The project consists of work on various roads throughout Bristol Connecticut. These locations are subject to change as conditions warrant. No pre-bid meeting is required for this contract. Liquidated damages of Two Hundred ($200.00) Dollars shall be paid by the Contractor to the City for each and every calendar day after the completion date hereinbefore specified. All or a portion of the liquidated damages may be abated for cause by agreement between the City and the Contractor. Liquidated damages will be deducted from monies due the Contractor before final payment. Work orders will be issued during the course of the agreement; said work orders may be issued any time through December 31, 2025, with all work assigned under such work orders completed within 30 days of assignment. Work not completed by the contract end date will not be completed by the contractor under this contract, and such work assignment will be considered rescinded. The successful Bidder/Contractor shall begin work within fourteen (14) calendar days after the contract signing. All work under the Contract is to be completed within ninety (90) calendar days from the date of the issuance of a work order The City reserves the right to waive any informalities in the bid, to reject any or all bids, and to accept the bid that in its judgment is in its best interest