Renovation of a residential development in Modesto, California. Completed plans call for the renovation of a residential development.

The City of Modesto Housing Rehabilitation Program provides financial assistance to eligible homeowners for the repair and improvement of their properties. Funded through federal resources, the program is designed to correct health, safety, and code deficiencies, extend the useful life of homes, and improve overall living conditions for low- to moderate-income households. The City is seeking qualified general contractors to participate by bidding on rehabilitation projects. Typical scopes of work may include roofing, plumbing, electrical, HVAC, accessibility improvements, and general property repairs. Question Deadline 09/25/2025 at 4:30 PM PT All questions regarding the Work Write-Up shall be submitted through online. This is a HUD-funded project. Section 3 businesses and/or businesses that employ Section 3 residents are strongly encouraged to respond. An engineer's estimate is NOT released for this project. The project is NOT subject to prevailing wage. Bidders are required to hold a valid General Contractor's Class "B" License. All General Contractors seeking to participate in the City of Modesto Housing Rehabilitation Program must maintain current insurance coverage as required by the City. Proof of insurance is a prerequisite for PINS (Public Improvement Notification System) approval and must be submitted prior to contract award. Addendum Issued (if required): September 26, 2025 Approximate Contract Award Date: November 2025 The Parties agree that ascertainment of the actual damages Owner(s) might sustain by such delay is difficult and impractical; therefore, the Parties agree that Contractor shall pay the owner the sum of $65 per day for each calendar day of delay until substantial completion of the work or termination of the Agreement. The Parties expressly agree that the sum stated is intended as liquidated damages and not as a penalty. In the event of whole or partial destruction the Owner(s) shall have the right to determine whether to complete construction. In the event, Owner(s) elects not to complete construction; the Owner(s) shall provide payment for the work performed to the date of notification to Contractor to cease construction. The tribunal may issue such orders for interim relief as the tribunal shall deem necessary to safeguard the property in dispute without prejudice to the rights of claimants or to the final arbitration decision in the matter. Any party who fails to appear after notice as provided herein, without obtaining a postponement from the presiding member of the tribunal, is deemed to have waived all rights to introduce evidence or to object to any part of the proceedings. Owner and Contractor acknowledge that this Agreement affects their legal rights and that they have read and understand its provisions. Owner hereby acknowledges receipt of "Notice to Owner" as mandated by Business and Professions Code Section 7018.5, explaining in non-technical language the key provisions of the mechanics' lien law and the rights and responsibilities of owners of property and contractors under agreements like this one.